Contract CONTRACT
THIS AGREEMENT,made and entered into this_18th_ day of_April_in the year Two Thousand
eleven by and between
THE OWNER: City of Salina
300 West Ash Street
Salina, Kansas 67401
THE CONTRACTOR:. THE PROJECT: #11-2860
Mid Continental Restoration Company Smoky Hill Museum
401 Hudson Rd 211 W Iron Ave
Fort Scott KS 66701 Salina KS 67401
SCOPE OF WORK:
The Contractor shall furnish all labor and materials,equipment and related services to perform and complete all of
the Work,as described by the proposal and Contract Documents entitled" Smoky Hill Museum exterior
restoration&sealing, Project#11-2860"and dated,9 February 2011, subject to the following:
It is hereby further agreed that the undersigned anticipates that materials and equipment will be on hand at the site
in sufficient quantities to commence construction on or before May 2,2011; and the completion of the
construction,ready for acceptance will be within-48—calendar days.
CONTRACT AMOUNT:
The Owner shall pay the Contractor for the faithful performance of the Work,upon satisfactory completion and
acceptance of the Owner,the total lump sum of"fifty seven thousand six hundred forty dollars&no cents"
($57,640.00),subject to additions and deductions by change order as provided in the conditions of the Contract
Documents.
CONTRACT DOCUMENTS:
The Owner and the Contractor agree that any reference herein to the Contract shall include all Contract
Documents listed and prescribed in the referenced General Conditions and the Contract Documents as fully as if
set out at length herein.
IN WITNESS WHEREOF,the parties hereto have caused execution of this instrument in three(3)original
counterparts as of the day and year above written.
CONTRACTOR: OWNER:
Mid Continental Restoration Company City of Salina
401 Hudson Road 300 West Ash Street
Fort Scott KS 66701 Salina,Ks,67401
s �
By�i��+1n idd' (.(f By
a� Uvi der ood kA w d o Y %rnG ntVtw Pn�e l
(printed name&title) e C+ 144CL KqA.A.-I Mayor
i' (printed name&title)
/ l ® DATE(MMMD/YYYY)
ACORN CERTIFICATE OF LIABILITY INSURANCE
7/1/201 t 4/26/2011
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed. If SUBROGATION IS WAIVED,subject to
the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the
certificate holder in lieu of such endorsement(s).
CONTA
PRODUCER Lockton Companies,LLC-1 Kansas City NAME_ T
444 W.47th Street,Suite 900 PHONE
N t A/C No):
Kansas City MO 64112-1906 EAWL
(816)960-9000 ADDRESS:
INSURER(S) AFFORDING COVERAGE NAIC#
INSURER A:Travelers Property Casualty Co of America 25674
INSURED MID-CONTINENTAL RESTORATION CO.,INC. INSURER 8:The IMelers Indemnity Co of America 25666
1063933 PO BOX 429 INSURER c:Everest National Insurance Company 10120
FT.SCOTT KS 66701 INSURER 0:
INSURER E:
INSURER F:
COVERAGES MIDCOI I V2 CERTIFICATE NUMBER: 11228189 REVISION NUMBER: XXXXXXX
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR TYPE OF INSURANCE ADD SUBR POLICY NUMBER POLICY ID EFF POLICY LIMITS
LTR
A GENERAL LIABILITY N N VTC2JCO-13IJ810A-TIL-10 7/1/2010 7/1/2011
DAMAGE TO RENTED
MMERCIAL GENERILITY PREMISES(Ea occurrence) $ 300,000
CLAIMS-MADE OCCUR MED EXP(Any one arson
X CONTRACTUAL PERSONAL&ADV INJURY s 1,000,000
GENERAL AGGREGATE $
GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG s 2-000,000
POLICY PRO LOC $
A AUTOMOBILE LIABILITY N N VTJCAP-131J8111-TIL-10 7/1/2010 7/1/2011
(Ea accident) $
}� ANY AUTO BODILY INJURY(Per person) $
ALL OWNED SCHEDULED BODILY INJURY Per accident
AUTOS NON-OWNED PROPERTY DAMAGE $ XXXXXXX
IX X HIREDAUTOS AUTOS
$ XXXXXXX
C UMBRELLA LIAR I OCCUR N N 7106000179101 7/1/2010 7/1/2011 EACHOCCURRENCE $ 5,000,000
X
X EXCESS LIAR CLAIMS-MADE AGGREGATE $
DED I X I RETENTION$ 10,000 $ xxxxxxx
WORKERS COMPENSATION OTH
B AND EMPLOYERS'LIABILITY N VTRHUB0012C45210(NE OK) 7/1/2010 7/1/2011 X TORY LIMIT ER
B ANY PROPRIETORIPARTNERIEXECUTIVE Y/N VTC2KUB8651B92A10(ADS)) 7/1/2010 7/1/2011 E.L.EACH ACCIDENT $
B OFFICER/MEMBER EXCLUDED? � NIA (EXCL.MONOPOLISTIC STAT S)
(Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000
If yes,describe under
DESCRIPTION OF OPERATIONS below EL.DISEASE-POLICY LIMIT
DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (Attach ACORD 101,Additional Remarks Schedule,H more space Is required)
RE:SMOKY HILL MUSEUM,SALINA,KS;MCR JOB#01-11-19356.
CERTIFICATE HOLDER CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
11228189 AUTHORIZED REPRESENTATIVE
CITY OF SALINA
300 WEST ASH STREET
SALINA KS 67401
ACORD 25(2010 105) The ACORD name and logo are registered marks of ACORD a 1988-2010 W11D CORPORATION.All rights reserved
�.. ✓ids y ��8( ll
Employers Mutual Casualty Company (NAIC #21415)
BUSINESS ADDRESS: P. 0. BOX 712, DES MOINES, IA 50306 - 0712. PHONE: (515) 280-2511. UNDERWRITING
LIMITATION b/: $85,636,000. SURETY LICENSES c,f/: AL, AK, AZ, AR, CA, CO, CT, DE, DC, FL, GA, HI, ID, IL, IN,
IA, KS, KY, LA, ME, MD, MA, MI, MN, MS, MO, MT, NE, NV, NH, NJ, NM, NY, NC, ND, OH, OK, OR, PA, RI, SC, SD,
TN, TX, UT, VT, VA, WA, WV, WI, WY. INCORPORATED IN: Iowa.
THE AMERICAN INSTITUTE OF ARCHITECTS
Bond No. S404741
AIA Document A312
Performance Bond
Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable.
CONTRACTOR(Name and Address): SURETY(Name and Principal Place of Business):
Mid-Continental Restoration Company, Inc. Employers Mutual Casualty Company
401 Hudson Road, PO Box 429 P.O. Box 712
Fort Scott, KS 66701 Des Moines, IA 50306-0712
OWNER (Name and Address):
City of Salina
300 West Ash Street
Salina, KS 67401
CONSTRUCTION CONTRACT
Date: April 18, 2011
Amount: $57,640.00 Fifty Seven Thousand Six Hundred Forty Dollars and 00/100
Description (Name and Location): Smokey Hill Museum, 211 W. Iron Ave., Salina, KS 67401, Smokey Hill
Museum Exterior Restoration & Sealing, Project#11-2860
BOND
Date (Not earlier than Construction Contract Date): April 26, 2011
Amount: $57,640.00 Fifty Seven Thousand Six Hundred Forty Dollars and 00/100
Modifications to this Bond: ® None ❑ See Page 3
•
TRACTOR AS PRINCIPAL SURETY
Company: (Corpo
�.
IVIid;p -tinental Restoration Company,once Seal) Employers Mutual Casualty Companyrate Seal)
S1.911Vure: Signature: .
Namle,ari itle: J. ran alsey Name and Title:De r -J. Sc rough.o
Preside Attorney-in-; (Any 6ddltlonal signatures appear on page 3) Surety Phone No. 515-280-2511
>�iaes� tic a
`=-'('FOR-INFORMATION ONLY-Name,Address and Telephone) OWNER'S REPRESENTATIVE (Architect,Enginedrorbther•
AGENT or BROKER: party) .
Lockton Companies, LLC
444 W. 47th Street, Ste 900
Kansas City, MO 64112-1906
816-960-9000
AIA DOCUMENT A312•PERFORMANCE BOND AND PAYMENT BOND•DECEMBER 1984 ED.•AIA
THE AMERICAN INSTITUTE OF ARCHITECTS,1735 NEW YORK AVE.,N.W.,WASHINGTON,D.C.20006 A312-1984 1
THIRD PRINTING•MARCH 1987
I The Contractor and the Surety, jointly and severally, which it may be liable to the Owner and, as
bind themselves, their heirs, executors, administrators, soon as practicable after the amount is deter-
successors and assigns to the Owner for the performance mined, tender payment therefor to the
of the Construction Contract,which is incorporated herein Owner; or
by reference. -2 Deny liability in whole or in part and notify the
2 If the Contractor performs the Construction Contract, . Owner citing reasons therefor.
the Surety and the Contractor shall have no obligation S If the Surety does not proceed as provided in Paragraph
under this Bond, except to participate in conferences as 4 with reasonable promptness.the Surety hall be deemed
provided in Subparagraph 3.1. to be in default on this Bond fifteen days after receipt of an
3 If there is no Owner Default, the Surety's obligation additional written notice from the Owner to the Surety
under this Bond shalt arise after: demanding that the Surety perform its obligations under
3.1 The Owner has notified the Contractor and the this Bond,and the Owner shall be entitled to enforce any
Surety a its address described in Paragraph 16 below remedy available to the Owner. If the Surety proceeds as
that the Owner is considering declaring a Contractor provided in Subparagraph 4.4,and the Owner refuses the
payment tendered or the Surety has denied liability, in
Default and has requested and attempted to arrange r
conference with the Contractor and the Surety to be whole or in part,without further notice the Owner shall be
held not later than fifteen days after receipt of such entitled to enforce any remedy available to the Owner.
notice to discuss methods of performing the Construc- 6 After the Owner has terminated the Contractor's right
tion Contract. If the Owner, the Contractor and the to complete the Construction Contract, and if the Surety
Surety agree,the Contractor shall be allowed a reason- elects to act under Subparagraph 4,1, 4,2, or 4.3 above,
able time to perform the Construction Contract, but then the responsibilities of the Surety to the Owner shall
such an agreement shall not►naive the Owner's right,if not be greater than those of the Contractor under the
any,subsequently to declare a Contractor Default;and Construction Contract, and the responsibilities of the
3.2 The Owner has declared a Contractor Default and Owner to the Surety shall not be greater than those of the
formally terminated the Contractor's right D complete Owner under the Construction Contract.To the limit of the
the contract. Such Contractor Default shall not be de- amount of this Bond, but subject to commitment by the
Glared earlier than twenty days after the Contractor and Owner of the Balance of the Contract Price to mitigation of
Sure-
the Surety have received notice as provided in Sub- costs and damages on the Construction Contract,the Sure-
paragraph 3.1; and ty is obligated without duplication for:
3.3 The Owner has agreed to pay the Balance of the 6.1 The responsibilities of the Contractor for correc-
Contract Price to the Surety in accordance with the tion of defective work and completion of the Construc-
Contract tion Contract;
terms of the Construction Contract or to a contractor
selected to perform the Construction Contract in accor- 6.2 Additional legal, design professional and delay
dance with the terms of the contract with the Owner. costs resulting from the Contractor's Default, and re-
4 When the Owner has satisfied the conditions of Para- sulting from the actions or failure to act of the Surety
graph 3, the Surety shall promptly and at the Surety's ex- under Paragraph 4; and
pense take one of the following actions: 6.3 Liquidated damages, or if no liquidated damages
4.1 Arrange for the Contractor, with consent of the are specified in the Construction Contract,actual dam-
p ages caused by delayed performance or non-perfor-
Owner, to perform and complete the Construction mance of the Contractor.
Contract; or
4.2 Undertake to perform and complete the Construc- 7 The Surety shall not be liable to the Owner or others for
Con-
tion Contract itself.through its agents or through rode- obligations of the Contractor that are unrelated to the Con-
g g g struction Contract, and the Balance of the Contract Price
pendent contractors; or shall not be reduced or set off on account of any such
4.3 Obtain bids or negotiated proposals from unrelated obligations. No right of action shall accrue on
qualified contractors acceptable to the Owner for a this Bond to any person or entity other than the Owner or
contract for performance and completion of the Con its heirs, executors, administrators or successors.
struction Contract, arrange for a contract to be pre- 8 The Surety hereby waives notice of any change,includ-
pared for execution by the Owner and the contractor ing changes of time, to the Construction Contract or to
selected with the Owner's concurrence,to be secured related subcontracts, purchase orders and other obliga-
with performance and payment bonds executed by a tions.
qualified surety equivalent to the bonds issued on the
Construction Contract, and pay to the Owner the 9 Any proceeding, legal or equitable, under this Bond
amount of damages as described in Paragraph 6 in ex- may be instituted in any court of competent jurisdiction in
cess of the Balance of the Contract Price incurred by the the location in which the work or part of the work is located
Owner resulting from the Contractor's default; or and shall be instituted within two years after Contractor
4.4 Waive its right to perform and complete,arrange Default or within two years after the Contractor ceased
for completion, or obtain a new contractor and with working or within two years after the Surety refuses or fails
reasonable promptness under the circumstances: to perform its obligations under this Bond,whichever oc-
curs first. If the provisions of this Paragraph are void or
.1 After investigation,determine the amount for prohibited by law,the minimum period of limitation avail-
AIA DOCUMENT A312.PERFORMANCE BOND AND PAYMENT BOND.DECEMBER 1984 ED..AIA
THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE.,N.W.,WASHINGTON,D.C.20006 A312-1984 2
THIRD PRINTING.MARCH 1987
able to sureties as a defense in the jurisdiction of the suit tractor of any amounts received or to be received by
shall be applicable. the Owner in settlement of insurance or other claims
10 Notice to the Surety,the Owner or the Contractor shall for damages to which the Contractor is entitled, re-
be mailed or delivered to the address shown on the sig- duced by all valid and proper payments made to or on
behalf of the Contractor under the Construction Con-
nature page. tract.
11 When this Bond has been furnished to comply with a 12,2 Construction Contract:The agreement between
statutory or other legal requirement in the location where the Owner and the Contractor identified on the sig-
the construction was to be performed,any provision in this nature page, including all Contract Documents and
Bond conflicting with said statutory or legal requirement changes thereto.
shall be deemed deleted herefrom and provisions con-
forming to such statutory or other legal requirement shall 12.3 Contractor Default: Failure of the Contractor,
be deemed incorporated herein. The intent is that this which has neither been remedied nor waived,to per-
Bond shall be construed as a statutory bond and not as a form or otherwise to comply with the terms of the
common law bond. Construction Contract.
12 DEFINITIONS 12.4 Owner Default: Failure of the Owner,which has
12.1 Balance of the Contract Price:The total amount neither been remedied nor waived, to pay the Con-
b the Owner to the Contractor under the tractor as required by the Construction Contract or to
payable Y perform and complete or comply with the other terms
Construction Contract after all proper adjustments thereof.
have been made, including allowance to the Con-
MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
(Space is provided below for additional signatures of added parties, other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corporate Seal)
Signature: Signature:
Name and Title: Name and Title:
Address: Address:
AIA DOCUMENT A312.PERFORMANCE BOND AND PAYMENT BOND-DECEMBER 1984 ED..AIA
THE AMERICAN INSTITUTE OF ARCHITECTS,1735 NEW YORK AVE.,N.W.,WASHINGTON,D.C.20006 A312-1984 3
THIRD PRINTING.MARCH 1987
THE AMERICAN INSTITUTE OF ARCHITECTS
Bond No. S404741
AlA Document A311
Labor and Material Payment Bond
THIS BOND IS ISSUED SIMULTANEOUSLY WITH PERFORMANCE BOND IN FAVOR OF THE
OWNER CONDITIONED ON THE FULL AND FAITHFUL PERFORMANCE OF THE CONTRACT
KNOW ALL MEN BY THESE PRESENTS: that Mid-Continental Restoration Company, Inc.
(Hero insert full namo and address or legal title of Contractor)
401 Hudson Road, PO Box 429 Fort Scott, KS 66701
as Principal, hereinafter called Principal, and, Employers Mutual Casualty Company
(Hero insert hM namo and address or legal We of surety)
P.O. Box 712, Des Moines, IA 50306-0712
as Surety, hereinafter called Surety, are held and firmly bound unto City of Salina
(Ftero insert ful namo and address or legal We of Owner)
300 West Ash Street Salina, KS 67401
as Obligee, hereinafter called Owner, for the use and benefit of claimants as hereinbelow defined, in the
amount of Fifty Seven Thousand Six Hundred Forty Dollars and 00/100
(Here insert a stun equal to at least one-half of the contract price) Dollars($57,640.00
for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators,
successors and assigns,jointly and severally, firmly by these presents.
WHEREAS,
Principal has by written agreement dated April 18, 2011 , entered into a contract with Owner
for
(Hera insert full nama,address and description of project)
Smokey Hill Museum, 211 W. Iron Ave., Salina, KS 67401, Smokey Hill Museum Exterior Restoration &
Sealing, Project#11-2860
in accordance with Drawings and Specifications prepared by
(Hero insert full namo and address or legal We of Architect)
which contract is by reference made a part hereof, and is hereinafter referred to as the Contract.
ALA DOCUMENT A311 PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND • ALA
FEBRUARY 1970 ED. • THE AMERICAN INSTITUTE OF ARCHITECTS,1736 N.Y.AVE,N.W.,WASHINGTON,D.C.20006
1
LABOR AND MATERIAL PAYMENT BOND
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that if Principal shall promptly make payment to all
claimants as hereinafter defined, for all labor and material used or reasonably required for use in the performance of the
Contract,then this obligation shall be void, otherwise it shall remain in full force and effect, subject, however,to the following
conditions:
1. A claimant is defined as one having a direct and the name of the party to whom the materials were
contract with the Principal or with a Subcontractor of the furnished, or for whom the work or labor was done or
Principal for labor, material, or both, used or reasonably performed. Such notice shall be served by mailing the
required for use in the performance of the Contract, labor same by registered mail or certified mail, postage prepaid,
and material being construed to include that part of water, in an envelope addressed to the Principal,Owner or Surety,
gas, power, light, heat, oil, gasoline, telephone service or at any place where an office is regularly maintained for the
rental of equipment directly applicable to the Contract, transaction of business, or served in any manner in which
2. The above named Principal and Surety hereby jointly legal process may be served in the state in which the
and severally agree with the Owner that every claimant as aforesaid project is located,save that such service need not
herein defined, who has not been paid in full before the be made by a public officer.
expiration of a period of ninety (90) days after the date on b) After the expiration of one(1)year following the date on
which the last of such claimants work or labor was done or which principal ceased Work on said Contract, it being
performed, or materials were furnished by such claimant, understood, however,that if any limitation embodied in this
may sue on this bond for the use of such claimant, bond is prohibited by any law controlling the construction
prosecute the suit to final judgment for such sum or sums hereof such limitation shall be deemed to be amended so
as may be justly due claimant,and have execution thereon. as to be equal to the minimum period of limitation permitted
The owner shall not be liable for the payment of any costs by such law.
or expenses of any such suit c) Other than in state court of competent jurisdiction in
3. No suit or action shall be commenced hereunder by and for the county or other political subdivision of the state
any claimant: in which the Project, or any part thereof, is situated, or in
a) Unless claimant, other than one having a direct the United States District Court for the district in which the
contract with the Principal,shall have given written notice to Project,or any part thereof, is situated,and not elsewhere.
any two of the following: the Principal, the Owner, or the 4. The amount of this bond shall be reduced by and
Surety above named, within ninety (90) days after such to the extent of any payment or payments made in good
claimant did or performed the last of the work or labor, or faith hereunder, inclusive of the payment by Surety or
furnished the last of the materials for which said claim is mechanics' liens which may be filed of record against said
made, stating with substantial accuracy the amount improvement, whether or not claim for the amount of such
claimed lien be presented under and against this bond.
Signed and sealed this 26th day of April, 2011.
ATTEST: Mid-Continental Restoration Company, I Of or,
(PrincipaQ ;' ;(Sea ' ' .r_� l
(Witness) •� ,� �`^�;' .>
J. ank Halsey Mue)President
WITNE Employers Mutual Casualty Company,
`;a'S�'"u�'•Cq 'sue _ G`j; � �? •i' -
yr."
OLAL
Debra J. 5calrbordugh Mue)Attorney,i� , ,
„r•
Surety Phone No. 515-280-2511
ALA DOCUMENT A311 PERFORMANCE BOND AND LA80R AND MATERIAL PAYMENT BOND • AIA
FEBRUARY 1970 ED. THE AMERICAN INSTITUTE OF ARCHITECTS,1735 N.Y.AVE,N.W,WASHINGTON,D.C.20008
2
. . 5 .
• e• • •• a •• e e • It e • e •
s rb' • �tss{{ , a5y 4,a- "r• ,, &_i d , # 5 "' k +"•<''.{.. ,tea �a < +' f :f"-.:3'1.°" e? y,'i a ���Jy.'»� f c^u t- �p ° ,+• 7 }rte'd+a`?�'i:' Y• s?`,-a,. ::xt> 0 ,w b
i '4�4b15Y.k !".:JJrybr9.r<...*'%1 m' 'F, I� '9• �/ ; �S - .�, .,. �y,; h .1}
,� -, a � d :Y a�nsurance �es� w ?9 4 5 7:8:2. k Y�,::
��
s�.x .:'••iii , r i.:,3 Y a ',�4_ a C'r1 {,; „.r R i f /'�
».� *r ,? X �, ;. Pa,Box71 •L?es Mornes;1A�50306 0712 �'s : .��,v�'",r ` �i? : > .:xr i}, r Aij. fr a :: .5:'„mod:,_J >t'_ 3�.�'.�<`.' X r:<`�i, .� ..'m x x'�, sr t&,,- r�i�I&I '. . ti, �.;::s . ;;:.y ;:: ?;; :.,, fc.
to r ,x , . CERTIFICATE.OF AUTHORfTY INQNID�UALYATT�QRNEY}IN FACTS _� �,� f faw.;s
....r V d+, 't N.vr4Y M a._ Aw.;M: : a,±.`ii..a+ .3r!LV r. Y. '.S.tr - ag,S., 3° .,. •i d A* ,:�X =e - .. d
`KNOW;ALL=MEN BYYYTH€SE PRESENTt that "���y ` ` �`' _ znKy z` R rfi:
< '{t k.4 ,s "rs"'.a r't,r -4'�-a tr. kt,.a �y r^ > � r a4„'.�'x•-.�' rY -,. i,yl{,,. ,� l _ 's,..: r7^'.4'�'''..:"*.' tl, c,. ,7i'�' h' }s^” .}:.-f':Y
> ,`:' r•9Y{*,- .:.'..'�.';t`I�k°r 'k:'4'� ,r�"> '!7� ip3^,�,5+.� p,Y,{ # u7i _ ` t3': :.1'�-� �` i,hti r 'tip+Sf :.�i ,.
L; �a,Employers Mutuat CasuaftyFCompany,an IowalC9rporatron fi;; � ,;; . :` < � z �- . . �._. �4 r' ;,: r
ti :: I, �.:. a a t . ., . ,�, w� 5 Dakota Frre>Insurance i.nmpany,a North Dakota;Corporation r ,{,
';'i2�,.EMGA5COlr>SUrance,Compa�y,an[owa:Cargotratton Z. .,� } .t. � ,
1, ,� �: r.: n _ *6:_-EJyIC.Prp a BrCasuatty Campany,art low+a Cor oration
1 Union Insurance C'ornpany otF.Provid6no0j an<.lowa Cor oiatron'. ;�4`-f .- .�,\ ,t. p <.- 'X ) , �'
%s - . •, , ,.K �.,, ...<a�;�;.;..,; < <:....w.>+. 1 Y I,..'H6imlitan Mutual lnsurance Company,an Iowa Corporation; r Y-. r
,A�4 Ifli bli,EMCASC0 Insurance Company,an Iowa Garporat on ' ; ,.YA .r'. �a ; �.;, ,; �: x��� ,� „-.,A>� � '• + # =
"r pr r, .g { ., nx r r Ly %' ? fi « e a K sas >s' •c.:
-#: 3z ti� s .:,{ :tv� ,. fn _':: .',,,; : i . ,°3*'..hwx3 3 e t", <e.a Y 4a:; >.:`.' 3 t . ,, �, ' _` ti :..,, i, a, 4 `h s 2 :c>.
t•:;,hereinafterfeferred;to,severall .as Co-- 'and�tectavelyas'-.Compan' "T, a ch,daesX,Ahesespresents make constrtute,arid app,ikt: r s.r u-i$
n,<-. t ,b Y f, r par!Yd
,tip?'�'7v = f .._ .jt^yy ,+...r^'`.Z1.i�,.:.<,j^x.`fk.+ti,. {.,.e;,,;Yi°y:..:.,�+r:,Y: .li A•l_ ^:cd �',;?i4.�i�.t,p^Z:l a,5_g M'X .vst r `� v:.h;. --:r S:S.s. :.mot i•"+�'k.'.•r-... c ' Lx^t '}..n•4RC ,::
'. KATHLEEN M COEN, MARY T,�,F�LANIGAN CLAUDIA MANDATO�CHRIST�Y M-MCCART, MELISSA D fEVANS DEBRA J � .- r F; to
v '-CA'RBOROUGH;f KATHY FAGAN NANCY A" CLOVERA.IAU.RA'M 'Ml1RREN,CHARISSA b LECUYER INpIVIDhJALLY, KANSAS_' r
CJT�r r L�`..:�,, ti g-�,...,, . 9� { 1 k ` ' t .m'--:` �,.'k �"r f +i.$ '"r*' zc �», f." -f i .�1 r c �2. ,y I,. ..'�a r -f .�„ ? S;'t -,'t
,�rY,r MISSQURI r ,_f'. P , t " x¢ ` i" j, �..I.��P`t*°s't+dt"'"i' s,.r*x➢. '? r..:. ;.:: .f". t3 i c...:�'~x t`.3.;':.:°c 4'"`i.. ::,..:a.. +x'A.r4":�;,. ASS, r �'i
;_=its±true<andaawful'attome.-in fact:with full .owerand autho[{. =COnferred;to si n,#seal;Jrid-execute itslawful;borids :tandertakin s'antl,, , obligatory instrun entsof a ;
' 4f;:; ;,..:',�s ';-�>X..¢;>- y.°�{ --_"-Y. :'" P.:; :.�;%,2 `�.,..t. x;#,=r g"-x{<•>m':,,Xr <; _d'r" :'�- ;h� r., : < .� t3 9 �,r o u ,,,.i a.
r srmllar nature,aslfoltows .. C r a ka fv i x x 't { #1^ �.r' w s� K tx xx wt . � ,? �` t ?r .: 7 +
-xyZ {,""n <&:{ t ,;� Ls1,7— . ;;, 4 . x .nG ,_,, ,„ C � K +> -:� y,,� +a - .- t-, a .
' -s,^r �`j.-{¢ ri '� -«.yfi•?, °�^s `" :}'w. }K ,3'.. f � '°� 9� �, ' Lam. NI� - �<T- � ^sue' x '.+..°fin•,r 7i y't
p i-g, f n,I, S! s•r �~ �+ { � m= ANY ANDsAL _BO Sa <, � . " cA
s x e r . ?, a , $
`k.;d':z <,.':•"�:,;fi-',..,- 'i�>..:_:.`, a f +T..:t:., '°,'rl..-�': r,,. ..:X .r`.3..:_:' i?.-w.�:.>. t»">_x''....: .Z°v sF''et y 'q, r^.s. » "ty 1... :SS.; >,
�°ssand.to`•bind`each Com an`thereb as full :and to the>same�extent as if such mst Drhdh s we're signed'rby the>duly authorized officers of each such,Company:and alt-of,
'X,'2,,..,,rr:.'�,?;;'1(4, -_ ,:+,d. ..%,.,f. .;r v�:': Y ..;;'x n :rl;...;, �t ?�::: .r"::�a..'"2°a ::..gr ;j�''•.'a".?.�" �t� 4•°�°: t };.. '?ik.;, :;f•"; t.r,^'
4?thesacts-of:said attorne arsualtt'to t[a authont�/here, !',tven_are here,:,ratrfied:and confirmed s � ' '"�, r$ .&, I, "
✓"r,� :`,;ry�c� ,*sr ^^aa,,yx;,Y�+p,}-e r Tao. :rL s ">?":'! ✓9c`4�^,�7� .`..;�'... 7+iY;: "A,Y.y°', ° ,''#, '-'Y' ^y'`Tr '} 1<a -i:.: r,, d 4y5• „"l f :55�'✓77
='*' Fcy s.`t fP..1+ > x ;'g 4 7°,t' Ax ''E "0$ 7a; ..:•ti °+f ?y) ",. Dq ^• :' v '� +,}'°}�" ,�"t"•'".4 '" 'S ". y r : < .11�,,: cx g; :,Fv r .1.,p�x¢,14g': ! f;.x. �` 'i` ,•e -' i *'�i ,� n :.: �>+ /"-° a r -_' z' v� ;.t` J° >,$` .. .,' ', f"_.:zE.r s t x
r Po��`� x.:, _,,�'(''X.b F, ,�-ky' r , .,y.. "qty t ..x+ ��.y,y '� S,.B'K ..;� , a.�,.a, � k<.°YkX,.r _ '< °=: .. ? `" 5�•p::J'1'^:
7. w z r .;;,s' � ` i'r� k x � � I ,rh'- � �e r r r a r d i.:
The authority hereby granted shalltexp�refF APRIL;1„2014.; �,�, s�untess-sooner reyr ked fi=R �;e ,
I Si ?,„.}..,y-�,.Yt r zi,gx: `•'� '',.'fv•. -::,d t!°r.�.•-: ,.d7,,"?,.%r .s,^z .?�',f:J �:�x✓".p•', '�° r;, ✓,s4 .:A'-�,� _x _.\ x d:�:�:r`V
"+J3'7q v .. x.s it i„q �,ux "�.,�„ v .g t'.,r ,� , ,�'a �-y°.. f �; ` : �,' §', L ?^ �i ,�.x �,t^,¢Qf x ,�'.,,, �”, r,� ,r°h -�.k -�i
1. W w ri� � p►UTHORI:T�Y FOR,POWER QF ATT{3RNEV ,,
:4 'a1 tx... ,"yca �'sbit {,. "4 "'4R°'^xar' ,.gat- a ,., a s)a ,ai^r °.a} .( ra 'uPty4Yi^ rNtk '',, ^s,,"c r^'..
AA.,. v;' , ,.:r,+;... r -..' :.. .N ,.;.,: 5, x,. e,. ....z.r .;. ,:,. ,e,... a ,fib i.,» Me,,,.,xa: -a w�-.':
:`:This>'Aower of-Aftorne is made and:;execuit d; ursuaiif to,and b .the.authont ofetheafallow'' -resolution of the Boards of Oiractors of each,of=the.Companies at„a?J,
x =regulariynseheduled meetrng°of each eompanytdrlly called and#leld rn".1999- � .A; � u � . , r :; t r
,AktSOLVED.Th'e,PresidentgandtChief ExecutivetOfficer'an :Vice,•President'the Treasurer and the Secrets of''Etnt. e'rs _'Mutual'Casuait;Comoan",,shall'have power s -,<
5<,,7x, � :.; r. Y e'nr,gyY ,✓a ,,�r a i, ;eG ,..•wa. r:.:y<4 ,.....�a ..:.Y r,r.,:,.;'Y a r.3�.'::':c •?{,',:'n 'X..:"
and aWfhoritV,to 1c a oint�attorneVs in faCt>and autt onze themlto,execute on behalf of:each Company a.rid attach she seal;of the GompanyK..thereto,`-bonds ands
*'�:r;a 4 :.: 4".� .c'��'...� ..YT'. .. f.: ,,:. ;.,r .,•.:31p.;. A ....1%'.":;;+""°F ...,...,':."''.-<.-rx.>< >.°�, '.::' .:.x.""-.. ^:.r-.' .e., ,.,..,:.�.,: a,,,,t :,
-x unde,akin sw'reco nuances contracts of mdemni and.otherrwntm s,.:.,.,I bli ato; inathe,nature.thereof`and 2,to remove;anysach=attorney in fact at;a,y jirne;a9, revoke_:`
g ' w.,:9 >., tY .. p, 9 t,,ry.t-�,;, ,, ,YI.?,.,t �,%. , :, r...;: H< , ,�;n
,`�xthe,rlower�and'authon':g'iven to him or her Attom 's<}n-fact skialt:havearrl1ower andmauthon{ty,,,sub ect to the terms and,limrtations;of�the'power-of-attorney issuetl to them °;
°.;^+c..cr'?5-<.',4 ., `,'.4' �;>`:.:a,., jp,,, .. t...'.� ;,a.x? .z.:,:;} r', ..�.t.!, 4,•'.,a ,�,, 1 Xp,.:, ,h .,:, a
r--to'execute and deliver 6W6,ehalf of the Com_an ,an6;0 fta` the seal;of�the.Gomn,lan thereto;°bantls,and.°unrlertakirtgs�"re :gnlzances;contracts of rnde;mnity and .,
+-,,'a,'',: A,-,i'.'. :.- ° .,.:'s. , .z °z: a<,;=,p.,. Y.:,. L:;;•i°" .:;:::.5'& A� .:r,{�;:. rzrtC Y,twYA...S, d.„z.:W";:,,.,. >.,t;. .,..r..:: .ai ...>%- other wntin` s obti ato in`tfie:n3tUre thereof',and an snch:rnstrument,bkecutedb»an 'suchgattome ;m-fact'shall be fu l,and,m'all,res. cts:'bindm ;:upon ihk' mpany,�'
::' • ,,a''<,, gx : d. ryc^�:s . °!: y.;'s z.',:v ,: .yam y^ '�*.. „'-',' , ;,,. , , Y x :,. « g.;
>Certrficafion as,to* validit of an: per of"attorne:.;authprrzad herein made:<b tan:officer.ofyEm_lo ers Mutual'Casualty Company shalt be fuliy,:antl rn allies cts
Y , y„^pow y:::x, ..t;::�,Y �.:. >� t Y, r,rK-�,. P§°$Y ; . -4:'; ,; x::.. v.:: .:,;.,..w
;s^ �� , a, ;.,
:bindln turr,,on thr .. man fiiei'facsimile or,m 6hanicall reproduced;srgnafure ofrsuch officer.whether:rnatle heretofore or;hereafter wherever;appearing,upon a, 11"
,.X',rw,, -:�i.,r T dn. Ai':1 p&,i ' -,.<..`.t' 7':.'•-:^;Ill .+f'; 'e.y X. A111..,,B a:i.F..7:.a xr,'`<'.4'..'+ a =tan.':-'ay : `m.;s� c_.r.,: l.A :;,:.°' ,k.-.-.... . :;;TY.,.�:,..y ?
�t�66rtrfied,co sof and/; owerof attome of the Corn an';ahaN.:be;vaildom brndrn u on the,Com an�;wrth fhe same force and affec#asahough manually affixed � -,;r >,:
:.�;"a,r.�-i.,:"r pY:"".-"p,Y°c y;'�. '�.,;.:<�+-az`T� ^p�: repyzty�.+.yjy°.A°a.y aA t7'�1> .r'�'+,?�"6Y•"°Y°g p'1 :XSt„'°••..y� p&.r�°!,i 4ay r..... y.,,,P-f11+1 :"e$: -., :• a�'T 7",-..'FT" -x C•:ti` ,r 1.w
IN:WITN WHEREUE,.the,Compa i s;have causect:these,,ptesents to,be signed for each by their officers as".shown and the':Gorpofaieseals to be...hereto;affixed ttii§_
S`*i d X1:8 f(tayOfr �^JA UA1�1 �: 2(711 _..stf -1:� ; ..: - � p'�pw 'O '� r �y t.,v'^' p. r+ `p: wt Y
*ts cR. f.J"= <',t"#'>=.;, r.°°�G '.Z.. 7 :;+ �. .�: � ,r .. yy .� " �..t- �, I _ `�":__ r t, -1 k� _:. °a,. s``.,. ti r:'4' ,
? 't`'r st'"f °.' .1 � 'o pp'Y .' .x, ,''C�', ji 1 'r + f. rh t#r' t .. f x sv y�{ ray 1' `r - :�1` � _.st x 1` J: .:};r.
z r y^;x ✓ Y � ,ra TT �y Y.(y:, 2 , -I, h r+
X.wS'.''rs, "YY��
5: . Seals ?_ < „ ,;, ` ,, , ,� � -i "Bruce C Kelie ¢ fiairman hg t ;. Mrehael reel;::/ U r r 11
-11'r`z¢ti r,. fy. t fINSU: ,.Yq�'-'ail C:E.CO' `C....; a�rY d;G t r fa r' 'tw >Y7 S .,;zn .iy.}t.. .�-zr ..s t .�'v'? 2 S .
. , 'SCO, w qq2 str �P ,„ oFq , �e ysi , cif Companies 2 r3 4 5& rPresitlent; gy Assistant Secretary . ��n ?," <-s;
-4 pPOPy':•`':?a." ,004A y,�i,.;a :on aq G X. Y; `,�-I a , . y ,. �� :° .. i I �'+�,�� o .; ' 9,;'t z x 'S ._Y
I"
a`.� �o .r ,�� �£:� ;°J o _o-o a� >� f: f {� i.ofCompany314Vice,ChaJemanand r. � r>�'s r,�„. , -t, 'w,. K� :3-',°'.
N Z 1136 XT953 k;.y r ' pCEO of Com an I; .. x „t ; :*x� t
SF L {T P Y 3 g 3 K?.Y' y
:t” o: M ...o :o <-. is °'2 y»' 'sz. ._.{ -2ro k. "'+'r ,<* a. °,� ..
r�:.. g c? r;3: .' t 2 ` }3�= :4'y� z', o - " �ti q f ; .' ' ' a a'' i :' `^r4'4 , � a r> s :
rY"t: Y ;r c r, a. ti 7 'I { x ,' 7 t- n 7 19 S. . c1 ? U S O 'x•`��'� ';, .t WP:} •dr,.' +its o.>:. , ;:�l X{o`w.P, �` M.�' 4..'�s •�`�:: .' ;i'i� �-.ie'`Ci 1.`,.- � - '- ;`g .:k w. h}r'• .•.� I',t.: Gl�
z''i?•,{. r"n , r �. - r,i ,r J',r„ rte.+ S xk, S c �.f.':ti 5 ::. s >:°2 �`.. g f Y f <} a' }
+.sr't-- A-� �.�, , +:mat t�;T I�.i,i a.'r, -�` ."', �'..-'sue,W.
s>`,a' i:'J,.r'a`-s.4°s..,. r'N i�.f eX... �" `s, q€ ? `a ✓6S ,< Yfi,.
a ,: �Ontthis 1;t3THdaYof JANUAfiY AD 2011 before me a r' :
r+.p t i i. t. � l , 'X Y T ,
,.a`5�nnN;FC :'��`KS�RgwtF ;Q�';-a'��e�s - pf ;Notan''}t?ublic4mtandrfpr the Staterof�towa'(�ersoriall .:a'r>eared.Bruce1G Kelle•:a .
=,x � °ff 3� ,�.,_Q;;4fl; s x, >° ���X .�.,� 9%fir ? Freel.who bemg..1 d`u.ly sworn„did"say that they are�ahl.._.knowri to met to be tfie
a :* .! �..
'<,-`" x ".ry; at ti,-, ' , ; b r, , : .�_ : ,�;{� hairman;.4 r”'srdent Vrce Charmian`and C.EO,7 and/or Assistant Secretary, respectwely,�of•
' � � � o � so � . ,_b.,.:�'• �� each of,The'Companies atlove thatthe sealss°affrxad to.this instrument are the seals of said
,A,_y,•. f G� �.* {* �.. 5`..�t� 4 y��..: 1 .:,.:1 4'�,...t k...n v..s: -x,. , ,
,,-+,gyp&&�,: r ,.h - °Kb�.,, S t<!`�yt :; - -s !.e.,
z J -° Iowa° ,.:: R H nn o . .. <..�o,NES•xo . � �< 4,corporatlons,r that said<instrument::was signed and sealed on behalf of eachr of the Companies
�I,:, 4 �"'.c1.vs i�'�r ;. t .,u"Gi.��,'`�. ,j A',ri.., .- i s-.:v. > F>F xi s-x .�: r a,IF,y t ,c 'r",v � x .' .�, � t 7'.. 1 Rl'''rautfiority�of>$err rrespective Boards of Directors and thatfhe sand'truce G I(elley and z
r r�„ r p,_ a,:;_t � t:,� Iichael,Ereel has_such toffeers,g acknowledge the execut}on of said instrument t, bexthe J.,
���u T !N� �� L�4 >" _ �l x =.voluntary act and deed of each of the;Companres , °�r :i a ?
ar . , , � �qt �v > « X� a ,. r,' t* erg - - srT Commission'Ex ires,Ocfober 1li,rr2011, ; Z'
;'.ibt r ,.>; "`.Y� jai,:. 2 '.. - °` �a�,;;si� Y -t- :1.1" ° t, c �,V:,# �ryt..; � r ���"�i F 4k�'i 7, xr�"t���. _ � ��;
f}.�'.s'�. �+< ''? m y:: # ,.., :: :s+...,•c r_. z ;'k'� .' "Y.<•ti w> .:x�."u�,S.?,'s� .� 's t"a ¢ a+`a ,, :. •t-.t a� {
1..;." �t° 2 �CtiER1�L Ct OWNOVER os_:; 0Z � � � z �1 „ ,, s,r
41'y'.,.. „y3a; ^.O ' r : .3 '±n ^,� ;.1' -)it), `'ti i ,.j''`<' Inµ S } ti -t ° ':",'h'1
11�''.` � .Ey#y, � ^t"-.:�� itt:"; :..�Y Cara.inisslon, F mber,7t9064 t ::�' a - c,A,L- sx, ,r.• e `r� x N3 a a a .. T "%'
s a4 AoF NSURAN e My CommY ExpOyt 16 2411E t w £ u , }
sM �a�` w .` Notary P in and for the State of►owa
T
,rPc a .°}C INE.S� deY;r) xy :j''# wa",'- ?':: , ¢M..0-'," 5 1 a .a :'.1, p..".,�}r <'. a'k �r >3 `,
f i`,`n&3 Ys � 3 s-2': S dA ? '°'' g'ms - .'t,', `r'"8s x. t s :v : 'r a �r':: ;�: t v, ''¢ It' si 41 r, skit CERTIFICgT;E4 to r ,�
,,., �,,I,'David L Hlxenbaugh;Vrce Presrtlentzof the Companies,do hereby certify thatthe foregoing resolution of the ABoards of.DirectOrs .by eacl;of the �,,r.
:.ps 7> •,.: A,�.," L rs�a,e'kr„ :�". �,..er'y a. + g`m..*' . :cb ,F-.'g 3 ,�,.::Fs s. ,., n `S .
Corn antes nd:tl is`Rawer o Attor`ne is"I'd' ursuar t theret' '111R�`R�.:1;�°° `:;w °r'r JANUARY'1.8, 2011 "r„ T r ; a
ff }
on behalf.of athleen&M ;Coen;N ary T I , ,, n, Claudia an a o° ri y; car,_ e issa vans, e ray ear oroug at y r j
:.� }'»x .:'; -x ,',: * ,H .:,r'{ ... 1 « .6 ..,::c`�,°,.fir.'is%°:'a 1., .„a F -.�:. Y::^ ,£` -* sue^,;i. +-2 rc .err' 1Q.a
;are true and correct`and-are.still in full fo ce and effect agan,gN±ancy A�Clover, Laura'M Marren, Chart ., D,Lecayer b Pr7 _m ”.x, ,
-t� L°:`:: '�'�Y.�"2* ' F.�.�S ✓�-S$, �;.i .'�r`i z rsa :. sa5u;: :m;. 4 ,fit:,.`' Y,`F r ,. ''' S �F'.v�j'-1:,•
In Testimony Whereoffl have sribscnbed;rtiV name and affixed,the<faesimile seal;of each Company.#his °i day of °d :` R F 1�a - . `
#{.- ,.'s ,i.A �^.� n E.a•, ,K.j a ,j� '"n «L` `�' yL y' X : +'ss -a :�:"'a °°n r`;',t �*`'t. ry�.S Yzy.
~1.,is ` '�,1� t_. ',,` r> r ;. 4 :. �w S�,.X�r'�31 r�'�: 2`° k� .✓'` � ,t< �. ,i,'� -:.,'�i J'a J '� 1 i �:1
y xa r { S a 3 �Y # i t 4 a k r >� ��8.. 2 t r P
c. -y, °, r c { tP. k. T� x 5 ... r' L ;.'. - ., ta 7�s. ` r•d Ai y ,µry{x .`, ��
z G .., rKah*.°tl>»_ a ;' ti-. � _ _ y,, Uice President k
� r �, > :.
PO Box 429
Fort Scott, KS 66701
�p� .
Ph: 620-223-3700
Fax: 620-223-5052
.. ,
TRANSMITTAL
MID-CONTINENTAL
RESTORATION CO.,INC.
www.midcontinental.com
Date: 4/27/11
City of Salina
Attn: Byron Ericson
300 West Ash St.
To: Salina, KS 67401 From: Clint Womeldorff
Company: Mid-Continental Restoration Co., Inc.
Phone #: Phone #: 620-223-9114
Fax #: Fax #: 620-223-5052
Project No. 11-2860 Email:
MCR Project#
WE ARE SENDING YOU:
COPIES DESCRIPTION
3 Signed Contract
1 Certificate of Insurance
1 P&P Bond
THESE ARE TRANSMITTED as checked below:
F1For Approval ❑Approved as submitted Submit copies for distribution
FEWFor your use F�Approved as noted ❑ Resubmit copies for approval
ElAs requested F] Returned for Corrections ❑ Retum corrected prints
REMARKS:
COPY TO File 01-11-19366